国际土木工程施工合同(中英文对照版)示范文本
土木工程施工合同
Contract for Works of Civil Engineering Construction
This CONTRACT is made on the _th of_(month), _(year) by and
between_(hereinafter called “Party A”) of the one part, and _(hereinafter called “Party B”) of the other part.
公司（以下简称“雇主”）与_公司（以下简称“承包商”）于_年_月_日特签订本合同。
WHEREAS 鉴于。。。
NOW THEREFORE THIS CONTRACT WITNESSETH that it is hereby agreed by and between the parties hereto as follows:
双方达成协议如下：
civil engineering 土木工程
Chapter 1 Definitions and Interpretation
Article 1 Definitions
In the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby assigned to them, except where the context
other requires:
定义
本合同（按下文所定义的）中的下列词和用语，除文中另有要求者外，应具有本条所赋予的含义：
“employer” means the person named as such in this contract and the legal successors in title to such person, but not (except with the consent of the Contractor) any assignee of such person.
“雇主”是指本合同所指明的当事人以及取得当事人资格的合法继承人，但除非承包商同意，不包括此当事人的任何受让人，本合同中的雇主为_(填入名称)。
“Contractor” means the person whose tender has been accepted by the Employer and the legal successors in title to such person but not (except with the consent of the Employer) any assignee of such person.
1.2承包商是指其标书已为雇主接受的当事人以及取得此当事人资格的合法继承人，但除非雇主同意，不指此当事人的任何受让人。本合同中的雇主为_(填入名称)。
“Subcontractor” means any person named in the Contract as a Subcontractor for a part of the Works or any person to whom a part of the works has been subcontracted with the consent of the engineer and the legal successors in title
to such person, but not any assignee of any such person.
1.3“分包商”是指本合同中指定作为分包工程某一部分的分包商的任何当事人，或由工程师同意已将工程的某一部分分包给他的任何当事人以及取得该当事人资格的合法继承人，但不指此当事人的任何受让人。
“Engineer” means the person appointed by the employer to act as Engineer for the purpose of the Contract and named as such in this Contract.
1.4“工程师”是指雇主为本合同目的而指定作为工程师。本合同中的工程师是指_(填入名称)。
“Engineer Representative” means a person appointed from time to time by the engineer under clause 9.2.
1.5“工程师代表”是指工程师根据9.2条款随时指定的人员。
“C ontract” means this Contract, the Specification, the Drawings, the Bill of Quantities, the Tender, the Letter of Acceptance, the Contract Agreement (if completed) and such further documents as may be expressly incorporated in the Letter of Acceptance or the Contract Agreement (if completed).
1.6“合同”是指合同，规范，图纸，工程量表，投标书，中标函，合同协议书以及其他明确列入中标函或合同协议书（如已完成）中的此类进一步的文件。“S pecification” means the Specification of the Works included in the Contract and modification thereof or addition thereto made under Clause 95 or submitted
常见的合同通用条款中英文对照
常见的合同通用条款 GENERAL TERMS AND CONDITIONS OF CONTRACT DATED日期 CONTRACT NAME合同名称 by and between合同双方 PARTY A NAME PARTY A甲方名称 and与 PARTY B NAME PARTY B乙方名称 TABLE OF CONTENT PRELIMINARY STATEMENT前言 1. DEFINITIONS定义 2. [OPERATIVE CLAUSES] 具体操作条款 3. CONDITIONS PRECEDENT如有必要，根据交易具体情况设定相应先决条件 4. REPRESENTATIONS AND WARRANTIES 陈述和担保［保证］ 5. TERM合同期限 6. TERMINATION合同终止 7. CONFIDENTIALITY保密义务
8. BREACH OF CONTRACT违约 9. FORCE MAJEURE不可抗力 10. SETTLEMENT OF DISPUTES争议的解决 11. APPLICABLE LAW 适用法律 12. MISCELLANEOUS PROVISIONS其他规定 THIS CONTRACT(“Contract”)is made in [city and province], China on this day of ,200 by and between [Party A name],[Party A entity form] established and existing under the laws of China, with its legal address at [address] (hereinafter referred to as “Party A”), and [Party B name], [Party B entity form] organized and existing under the laws of [Party Bjurisdiction of incoporation] with its legal address at [address] (hereinafter referred to as “Party B”). Party A and Party B shall hereinafter be referred to individually as a “Party ” and collectively as the “Parties”. 本合同于年月日由以下两方在［地点］签订： ［甲方名称］，一家根据中华人民共和国法律组建及存续的［甲方组织形式］，法定地址为［甲方法定地址］（以下简称“甲方”）： ［乙方名称］，一家根据［乙方所在国］法律组建及存续的［乙方组织形式］，法定地址为［乙方法定地址］（以下简称“乙方”）。 甲乙双方以下单独称为“一方”，合称为“双方”。 PRELIMINARY STATEMENT 前言 [add background information if appropriate]［视交易具体情况决定是否应介绍合同背景］ After friendly consultations conducted in accordance with the principles of equality and mutual benefit, the Parties have agreed to [describe subject matter of the Contract] in accordance with Applicable laws and the provisions of this Contract. 双方本着平等互利的原则，经友好协商，依照［相关法律名称］以及其他有关法律，同意按
中英文对照三方合同
租赁合同 LEASE CONTRACT 出租方(甲方)： Land Lord (Party A)： 承租方（乙方）： Tenant (Party B)： 中介方(丙方)： Intermediary(Party C)： 根据国家有关法律、法规和本市有关规定，甲、乙双方在平等自愿的基础上，经友好协商，就甲方将其合法拥有的房屋出租给乙方使用，乙方承租使用甲方房屋事宜，订立本合同。Party A and B have reached an agreement through friendly consultation to conclude the following contract. 1、房屋地址Location of the premises 甲方将其所有的位于的房屋及其附属设施在良好状态下出租给乙方作_______使用。 Party A will lease to Party B the premises and attached facilities owned by itself, which is located at__________________________________________on for _________ 2、房屋面积Size of the premises 出租房屋的登记面积为平方米（建筑面积）。 The registered size of the leased premises is_____quare meters (Gross size). 3、租赁期限Lease term 租赁期限自_____年____月____日起至______年____月____日止，甲方应于______年_____月_____日前将房屋交付乙方使用 The lease term will be from (month) (day) (year) to_______(month)_______(day) ______(year). Party A will provide it to Party B for use before______(month)_____(day)_____(year) 4、租金Rental 1)、金额：双方商定月租金为，付费方式为，提前____天支付下一期租金。 Amount：the rental will be RMB per month. Payment of rental will be one installment every_______month(s), Each successive installment will be paid______days before the starting date of successive period. 5、押金Deposit 1)、为确保房屋及其附属设施之安全与完好，及租赁期内相关费用之如期结算，乙方同意于______年_____月日前支付给甲方押金元整，甲方在收到押金后予以书面签收。
中英文对照版合同翻译样本
1.Sales Agreement The agreement, (is) made in Beijing this eighth day of August 1993 by ABC Trading Co., Ltd., a Chinese Corporation having its registered office at Beijing, the People’ Repubic of China (hereinafter called “Seller”) and International Tradi ng Co., Ltd., a New York Corporation having its registered office at New York, N.Y., U.S.A. (hereinafter called “Buyer”). 2.WITNESSETH WHEREAS, Seller is engaged in dealing of (product) and desires to sell (product)to Buyer, and WHEREAS, Buyer desires to purchase(product) from Sellers, Now, THEREFORE, it is agreed as follows: 3.Export Contract This Contract is entered into this 5th day of August 1993 between ABC and Trading Co., Ltd. (hereinafter called “Seller”) who agrees to sell, and XYZ Trading Co., Ltd. (hereinafter called “Buyer”) who agrees to buy the following goods on the following terms and condition. 4.Non-Governmental Trading Agreement No. ＿＿This Agreement was made on the＿day of＿19＿, BETWEEN ＿ (hereinafter referred to as the Seller) as the one Side and ＿ (hereinafter referred to as the Buyer) as the one other Side. WHEREAS, the Seller has agreed to sell and the buyer has agreed to buy ＿ (hereinafter referred to as the Goods ) the quantity, specification, and price of which are provided in Schedule A. IT IS HEREBY AGREED AS FOLLOWS: 5.Contract For Joint-Operation Enterprise ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registered office at (hereinafter called “Party A”) AND ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registere d office at (hereinafter called “Party B”) Party A and Party B (hereinafter referred to as the “Parties”) agree to jointly form a Co-operation Venture Company (hereinafter referred to as the “CVC”) in accordance with “the Laws of the People’s Republic of C hina on Joint Ventures Using Chinese and Foreign Investment” and the “Regulations for the Implementation of the Laws of the People’s Republic of China on Joint Ventures Using Chinese and Foreign Investment” and other applicable laws and regulations. 6.MODEL CONTRACT Contract No. Date: Seller: Signed at: Address: Cable Address: Buyer: Address: Cable Address: The Seller and the Buyer have agreed to conclude the following transactions according to the terms and conditions stipulated below: https://www.sodocs.net/doc/fb173270.html, of Commodity: 2.Specifications: 3.Quantity: 4.Unit Price: 5.Total Price: U.S.$: 6.Packing: 7.Time of Shipment: days after receipt of L/C. 8.Loading Port & Destination Port: From via to . 9.Insurance:
国际贸易合同中英文对照版
编号：_______________ 本资料为word版本，可以直接编辑和打 印，感谢您的下载 国际贸易合同中英文对照版 甲方：___________________ 乙方：___________________ 日期：___________________
英文进口合同范本-- 合同编号(Contract No.): 签订日期（Date） : ________________
m 甘售 inr (signed a ° ________ __ The Buyer _________________________________________
Address- C >5H (T E _) -—— ________ f
卖方: The Seller: 地址: Address: 电话(Tel):_ 传真(Fax): 电子邮箱(E-mail):
买卖双方同意按照下列条款签订本合同: The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: 1. 货物名称、规格和质量( Name, Specifications and Quality of Commodity ): 2. 数量(Quantity ): 允许的溢短装( % more or less allowed ) 3. 单价(Unit Price ): 4. 总值(Total Amount ):
(完整版)商品买卖合同(中英文对照)
商品买卖合同 合同编号(Contract ):NO Goods Sales Contract 买 方(Buyer): 营业执照号码(身份证号) Business License No.（ID No.）: 卖 方(Seller)： 营业执照号码Business License No.： 签订时间Signing date ： 签订地点Signing place ： 经双方协商同意，按照<<中华人民共和国合同法>>，签订本合同，并严格遵守履行。 一、标的、金额 the subject and amount 买方向卖方购买如下商品： 货 号 Item No 商 品 名 称 Description 型 号（规格）Mode l No.(specification)） 数 量 Quantity 单 位 Unit 单 价 Unit price 金 额A mount 备 注Rem arks 合计人民币金额(大 写): 佰 拾 万 仟 佰 拾 元整 (空格不够，可附页。凭样定货的，双方可另附约定。) 二、交提(货)日期 Goods delivery date or delivery time 交提(货)时间： 年 月 日，卖方经买方同意，可提前供货。 三、交提(货)地点 Goods delivery place : 。 四、交提(货)方式 Means of goods delivery :第 种 1.卖方送货 2.卖方代运3.买方自提4.其他 。买方收货时，由收货员签字，在送货单上加盖公章或收货专用章。 五、 商品质量（标准）The commodity quality (standard):第 种1.国家标准2.行业标准3.企业标准4、样品标准5、双方另行约定 。凭样交货的商品，应与双方确认的样品及其说明的质量相同，样品应当由双方签章封样保存。如对商品有特殊要求的，可另行约定。合格率低于 ℅为该批商品不合格，买方有权拒收。 六、商品验收Goods inspection and acceptance 验收时间：第 种1.当场验收2. 交货日前 天内验收3.交货后 天内验收。验收方法：第 种1.逐件2.抽样3.其他
英文销售合同_中英文对照销售合同范本
英文销售合同_中英文对照销售合同范本英文销售合同_中英文对照销售合同范本(一) SALES CONTRACT 合同编号： Contract NO: 签订地点： Signed at: 签订日期： Date: 买方： The Buyers： 卖方： The Sellers： 双方同意按下列条款由买方售出下列商品：
The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as set forth below： (1)商品名称、规格及包装 (1)Name of Commodity ,Specifications and Packing (2)数量 (2)Quantity (3)单价 (3)Unit Price (4)总值 (4)Total Value (装运数量允许有 %的增减) (Shipment Quantity %more or less allowed) (5)装运期限：
(5)Time of Shipment： (6)装运口岸： (6)Port of loading： (7)目的口岸： (7)Port of Destination： (8)保险;由方负责，按本合同总值110%投保_____险。 (8)Insurance：To be covered by the___for 110% of the invoice value against_______. (9)付款：凭保兑的、不可撤销的、可转让的、可分割的即期有电报套汇条款/见票/出票____天期付款信用证，信用证以_____为受益人并允许分批装运和转船。该信用证必须在______前开到卖方，信用证的有效期应为上述装船期后第15天，在中国______到期，否则卖方有权取消本售货合约，不另行通知，并保留因此而发生的一切损失的索赔权。
中英文进口合同范本
中英文进口合同范本 以下是关于《中英文进口合同范本》，供大家学习参考！ Purchase Contract 合同编号(Contract No.): _______________ 签订日期(Date) :＿＿＿＿＿＿＿＿＿＿_ 签订地点(Signed at) :＿＿＿＿＿＿＿____ 买：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ The Buyer:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 电话(Tel):___＿＿＿＿＿＿＿＿传真(Fax):＿＿＿＿＿＿＿＿＿＿ 电子邮箱(-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 卖：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ The Seller:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
＿＿＿＿＿＿＿ 地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿_＿ 电话(Tel):_＿＿＿＿＿＿＿＿传真(Fax):＿＿＿＿＿＿＿＿＿＿＿ 电子邮箱(-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 买卖双同意按照下列条款签订本合同： The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: . 货物名称、规格和质量： . 数量： 允许＿＿＿＿的溢短装 . 单价： . 总值： . 交货条件(Terms of Delivery) FOB/CFR/CIF＿＿＿＿＿＿＿ . 原产地国与制造商(Country of Origin and Manufacturers):
外贸合同中英文对照
S ALES CONTRA C T NOo : BS0812 5 DATE： NOV. 6 , 2008 THE S ELLER： BLUE SKY INTE R NATI0 NAL TRADING CO o ,LTD ? 118# 5TH NORTH RI NG ROAD, BE I GINQ P.R. CHINA THE BUYER： STAR CORPORATION 5 KINGROA D DU BAI, UAE T h i s C o ntra c t is made by and b e tw e e n the Buyer and S e llei; wh e reby the Buy e r agree to bu y and the Seller a gree to sell the un d ermen tioned c ommodity a c c ording to t lie term s a nd co n ditions st i pulat e d b e 1 o w 数量和金额可以上下浮动5% P A C K I NG： 2 0 piece s of Baby B 1 anke t s a r e p acked i n one
expo r t sta n dar d c a rt o n, solid co 1 or and s ize i n the s a me c a r ton. 包装：2 0条童毯被装进-项输出品标准硬纸盒、一样颜色利尺寸的装在相同的硬纸盒。 MAR KS： Shipping m a rk i n c 1 udes S TAR ,S/C No。,sty 1 e No o , port o f des tina t ion and c a r t on N o .陵头：运输吱头包括S TA R （公司名）、合同（sal e s contract）号码，款式号码，目的港和纸箱号码 Side mark m u st s how the co 1 o r t the s i ze of c a rton and p i ece s p e r carto n ? 侧唆头必须显示纸箱颜色，规格和每箱（童毯）条数 T I ME OF SHIPMENT：装运期 Wi t liin 60daysupon receip t o f the L / C wh i c h acc ord with relevant c buses o ft h i s Contract。收到符合合同的信用证^六十天内 POR T OF LOADI NG AND DESTINAT I ON：FromTianj i n, Chi nato Dub a i, UAE 装运港目的港 T r an s shipment i s all owed an d p artial shipme nt i s pro h i b i te d o 转运被允许，而且分批装运被禁止. IN S URANCE： To beeffecte d b y the Sei 1 e r for 1 1 0% o f inv o i c e value c ov e r in g Al 1 Ris k s and War Risk s a s p er CIC o f PICC d ated 01/01/1981.保险：卖方按合同金额的110%投保包含的一切险和战争险依照1981年的P I CC规则的CIC条约。 TERMS OF PAYMENT： By irrev o c able Let t er of Cre d i t at 60 d ay s a f t er s igh t, reaching the S e 1 1 er not 1 a te r t han Nov.30, 200 8 an d rem a in i ng v a li d f or n e gotiation in Ch i n a fo r f ur t her 15 days after th e a ffected s hipment o I n c a se of late ar r i v al of the L/C, the Se 1 1 er s hall not be liable for any d e lay i n ship me n t and shall ha v e the right t o res c i n d the c o ntra c t and / o r c 1 aim for damages0付款期限：不可撤销信用证，见票后6 0天付款.卖方收到信用证不得晚于08年月30号.偿付通知议付在中国装船后15天内提交单据，如果信用证迟到,卖方将不负责装船中的任何延迟而且将有权利废止合同和I或损害要求（赔偿）。 DOCUMENTS：文件 +Si g n e d invoice i n t r ipli cate, one or i g i nal o f w hicli s lioul d b e c ertifiedby Chamber of Com mere e o r CCPIT an d legalize d b y UAE em b ass y/co n su 1 ate in sei 1 er's country ? +签署的单据一式三份，一份正本应该被商会或CC PIT （贸促会）检定而且在卖方的国家被阿拉伯联合大公国大使馆I领事法律上认为正当。 +Ful 1 set （3/3） of c 1 ean on board o cean b i 11 o f lading ma r k e d <4fr e ight pr e paid" made out t o orde r blank en d o r sed n o t i fying th e app 1 icant. +全套（3 I 3）清洁海运提单标记"船货预付”空白抬头提单通知申请人。 +In s u r a n ce polic y i n dup lica te end o r s ed in b 1 a nk. +保险单一式两份空白背书。 +P a c k ing list i n t r i p 1 i c ate o +包装目录一式三份 + Cer t if i c at e of ori g in c erti f i e d by Cham b er of C o mmerce o r C CP I T and 1 e ga 1 i zed by U AE em b as s y/consulate in s e lie r "s countr y ?
中英文对照合同11
采购合同 (Purchasing Contract) 合同编号(Contract NO.)： 合同签订地点(Signed At)：东营 签订时间(Date)：年月日出卖人(Seller)： 买受人(Buyer)： 鉴于：根据【中华人民共和国合同法】及相关法律法规，本着平等自愿、等价有偿、诚实诚信的原则，经双方协商一致，订立本合同。 According to the Contract law of the People's Republic of China and relevant laws and regulations,we conclude the contract on the basis of equality, voluntariness,compensation of equal value and sincerity. 第一条标的、数量、价款及交（提）货时间 Item 1 (object)Quantity Price and Delivery time 物资编码名称及规格型号Commodity code and type 生产厂家 Manufacture r 计量单位 Unit 数量 Quantity 单价（元） Unit Price 总金额（元） Total Amount 备注 Note 不含税总金额（人民币） Total Amount (V AT excluded) 交提货时间、数量：年月日至年月日全部交货。 Delivery time: From to 第二条质量标准：标准代号、编号和标准名称：GB150-98. Item 2 Quality standard: standard code,serial number and standard name:GB150-98. 第三条出卖人对质量负责的条件及期限 Item 3 Conditions and time limits that Sellers shall be held responsibility for 1. 质量负责条件和期限按正常运行12个月止执行。 1. Quality responsible conditions and time limits shall not be valid until the product has been functioning properly for 12 months 2. 出卖人对标的物的质量负责，产品均附质检报告单，质量保证书。如果出卖人知道或 者应当知道所处卖产品存在质量缺陷，所承担的质量保证期限不受前款质量负责期限的约束，应依法承担相应责任。 2. Sellers shall be responsible for the quality of the marks.The products should include the Quality Inspection Report and Quality Guarantee.If the sellers know or should know the products they sell with defects in quality,the quality assurance time limits should not be subject to the previous quality responsibility deadline and they should be held due responsibility for it. 第四条包装标准：标准包装，产品所需包装由出卖人合理包装，适合水运和长途内陆运输，防潮，防湿，防锈，防震。 Item 4 Packaging standard: Standard packaging, the sellers should package the products properly, it should be suitable for shipment and long distance inland transportation. The packaging of the products should be resistant of dampness, moisture, rust and shock. 第五条随机的必备品、配件、技术资料、工具数量及供应方法：随设备交货一起交齐。 Item 5 The accompanied necessary materia l, accessories, technical information ,quantity of
中英文对照工程施工合同2范本
工程施工合同 Contract 合同编号( Contract NO. )： 签订日期( Date )： 发包方（简称甲方） Party A: 承包方（简称乙方）： Party B: 根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。 According to “P.R.C Contract Law”,and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect. 1.工程概况 Project overview 1.1工程名称： Project name: 1.2工程地点： Project location: 1.3工程范围： A. 新研发中心和新厂房的网络综合布线系统的施工； B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。 Project contents: A. The new R & D and new plant construction of network cabling systems; B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems. 1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。 Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.
三方合同-中英文版讲课稿
三方合同-中英文版
三方合同 Triangular Contract 本合同议于______年____月____日在______（地点）由有关三方在平等互利基础上达成，按三方同意的下列条件发展业务关系：This contract is made and entered into by and between the three parties concerned on ___________ (Date) in ________ (Place) on the basis of equality and mutual benefit to develop business on terms and conditions mutually agreed upon as follows: 1.合同三方 1.The Parties Concerned 甲方： Party A: 地址: Add: 2 电话： Tel.: 传真： Fax.: 乙方： Party B: 地址: Add: 电话： Tel.: 传真： Fax.: 丙方： Party C: 地址: Add:
电话： Tel.: 传真： Fax.: 2.委任 2.Appointment 甲方为乙方在某地建立XX产线提供相关的技术支持、文件支持。乙方承诺从甲方处以散件形式采购xx，甲方将XX以散件形式发给丙方，丙方收到后在某地按甲方或乙方的技术要求组装成SKD形式产品发至乙方。 Party A provides relevant technical support, documentation support for Party B to set up a CKD XX product production line in place name. Party B should purchase XX product from Party A in CKD format. Party A should send the XX product to Party C in CKD format. Party C should assemble it accord to Parties A & B’s technical requirements and send it in SKD format to Party B. 3.商品：XX https://www.sodocs.net/doc/fb173270.html,modity: 4.数量：每年至少4万台 4.Minimum Quantity per year : 40,000pcs /year 5.价格条款 5.Price conditions 考虑到竞争对手的价格，甲方必须保证给乙方最有竞争力价格。每个产品的价格应由甲乙双方协商确定，甲方和乙方必须就每个季度的采购计划达成一致，以避免价格波动。每当原材料成本总变动变动+/- 3％时，所有产品的价格应每季度协商一次。 Part A must guarantee the best price to the part B, considering the Competitors’ prices.
国际贸易合同协议书样本中英文对照
国际贸易合同协议书样本中英文对照 文件编号TT-00-PPS-GGB-USP-UYY-0089
CONTRACT NO.: DATE: THE BUYERS: ADDRESS : TEL: FAX: THE SELLERS: ADDRESS: TEL: FAX: This Contract is made by and between the Buyers and the Sellers, whereby the Buyers agree to buy and the Sellers agree to sell the under mentioned commodity according to the terms and conditions stipulated below: 买方与卖方就以下条款达成协议： 1. COMMODITY: 2. COUNTRY AND MANUFACTURERS: 原产国及造商： 3. PACKING: To be packed in standard airway packing. The Sellers shall be liable for any damage of the commodity and expenses incurred on account of improper packing and for any rust attributable to inadequate or improper protective measures taken by the sellers in regard to the
进口合同中英文对照contract
CONTRACT 合同号Contract 日期Date: 地点：Place: 卖方：The Seller: 地址：Address: TEL: FAX: 买方：The Buyer: 地址：Address: TEL: FAX: 本合同由买卖双方缔结，按照下述条款，卖方同意售出，买方同意购进以下商品： The Seller agrees to sell and the Buyer agrees to buy the under mentioned goods subject to terms and conditions set forth hereinafter as follows: 1.商品名称及规格NAME OF COMMODITY AND SPECIFICATION: 2.数量QUANTITY: 3.单价（包装费包括在内）UNIT PRICE (PACKING CHARGES INCLUDE): 4.总值: TOTAL VALUE: USD 5.包装（适于海洋运输）PACKING (SEAWORTHY):
6.生产国别及制造商COUNTRY OF ORIGIN & MANUFACTURE: 7.装运时间：TIME OF SHIPMENT: 8.装运口岸：PORT OF LOADING: 9.目的口岸：PORT OF DESTINATION: 10.装运唛头：SHIPPING MARKS 11.付款条件：Terms of Payment A. 买方于装运时间前天通过银行开出以卖方为受益人的不可撤销的信用证，卖方在装船启运后凭本合同条款12所列单据在开证银行已付货款。信用证有效期为装船后15天截止。 A. days prior to the time shipment, the Buyer shall open with the Bank of , an irrevocable Letter of Credit in favour of the Seller payable at the issuing Bank against presentation of the shipping documents as stipulated under Clause 12 of this Contract after departure of the carrying vessel. The said Letter of Credit shall remain in force till the 15th days after shipment. B. L/C AT SIGHT 见票即付信用证（或者根据实际情况改为TT） 12.装运单据Shipping Documents: DETAILED IN THE L/C 按信用证所列 13.延期交货及罚款：除不可抗拒原因外，如卖方不能如期交货，买方有权撤销或解除该订单，或经买方同意在卖方缴纳罚款的条件下延期交货。买方可同意给予卖方天优惠期。每迟延一天卖方需向买方支付订单总价款%的违约金。罚款自第天起计算。 Delayed Delivery and Penalty: Should the Sellers fail to effect delivery on time as stipulated in this Order owing to causes other than Force Majeure as provided for in Clause 11 of this Order, the Buyers shall have the right to cancel or terminate the order .The Sellers may, with the Buyers’consent, postpone delivery on payment of penalty to the Buyers. The Buyers may agree to grant the Sellers a grace period of days. Delay each day, the Seller need to pay % of the price （the compensation）to the Buyer. Penalty shall be calculated from the 16th day. 13、仲裁：凡因本合同引起的或与本合同有关的任何争议，均应提交中国国际经济贸易仲裁委员会天津国际经济金融仲裁中心，按照申请仲裁时该会现行有效的仲裁规则进行仲裁。仲裁裁决是终局的，对双方均有约束力。 Arbitration: Any dispute arising from or in connection with this CONTRACT shall be submitted to CIETAC Tianjin International Economic and Financial Arbitration Center for arbitration which shall be conducted in accordance with the Commission’s arbitration rules in effect at the time of applying for arbitration. The arbitral awards is final and binding upon all parties 。 14. 商检条款INSPECTION: