国际土木工程建筑承包合同(中英文对照)

国际土木工程建筑承包合同（中英文对照）

PART工GENERAL CONDITIONS

第一章总则

DEFINITIONS AND INTERPRETATION

定义和释义

（1）In the Contract，as hereinafter defined，the following words and expressions 1．

shall have the meanings hereby assigned to them，except where the context otherwise requires：

1．1在本合同中，除按上下文另具意义者外，下列词语应解释如下：

（a）'Employer' means the party named in Part II who will employ the Contractor and the legal successors in title to the Employer，but not，except with the consent of the Contractor，any assignee of the Employer．

“业主”指第二章中所指定的雇用承包人的一方或其权利继承人，但不包括业主的受让人，经承包人同意者除外。

（b）“Contractor”means the person or persons，firm or company whose tender has been accepted by the Employerand includes the Contractor’s personal representatives，successors and permitted assigns．

“承包人”指标书已被业主接受的某个或某些人、商行或公司，包括其个人代表，继承人和业经认可的受让人。

（c）“Engineer”means the Engineer designated as such in Part II，or other Engineer appointed from time to time by the Employer and notified in writing to the Contractor to act as Engineer for the purposes of the Contract in place of the

Engineer、designated．

“工程师”指第二章中所指定的工程师，或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其他工程师。

（d) 'Engineer’s Representative' means any resident engineer or assistant of the Engineer or any clerk of works appointed from time to time by the Employer or the Engineer to perform the duties set forth in Clause 2 hereof，whose authority shall be notified in writing to the Contractor by the Engineer．

“工程师代表”指任何常驻工程技术人员、工程师助手，或由业主或工程师随时任命履行本合同第二条规定职责的任何工程现场监督，其权限应由工程师书面通告承包人。

（e) “Works” shall include both Permanent Works and Temporary Works，

“工程”包括永久性工程和临建工程。

（f）“Contract” means the Conditions of Contract，specification，Drawings，priced Bill of Quantities，Schedule of Rates and Prices，if any，Tender，Letter of Acceptance and the Contract Agreement，if completed．

“合同”指合同条款、技术规范、图纸、标价的建筑工程清单、单价和价格表（如果有），还可指标书、接受证书以及承包协议（如已完成）。

（g) “Contract Price” means the sum named in the Letter of Acceptance, subject to such additions thereto or deductions therefrom as may be made under the provisions hereinafter contained．

“合同价格”指在接受证书中确定的数额，可按本合同以下条款规定增减。

（h)“Constructional Plant' means all appliances or things of whatsoever nature required in or about the execution or maintenance of the Works but does not include materials or other things intended to form or forming part of the Permanent Works．

“建筑设备”指工程施工和维修中或有关施工和维修所需的全部设备或物品，不论任何性质，但不包括旨在构成或正在构成永久性工程某一部分的材料或其他物品。

（i）“Temporary Works' means all temporary works of every kind required in or about the execution or maintenance of the Works．

“临建工程”指工程施工或维修或有关工程施工或维修所需的各种临时工程。

（j）“Permanent Works”means the permanent works to be executed and maintained in accordance with the Contract．

“永久性工程”指按合同将施工和维修的永久工程。

（k）“Specification” means the specification referred to in the Tender and any modification thereof or addition thereto as may from time to time be furnished or approved in writing by the Engineer．

“技术规范”指在标书或任何标书更改中提及的规范，或由工程师随时可能增加或书面同意增加的部分。

（1）“Drawings” mea ns the drawings referred to in the Specification and any modification of such drawings approved in writing by the Engineer and such other drawings as may from time to time be furnished or approved in writing by the Engineer．

“图纸”指技术规范中规定的图纸，经工程师书面同意对此种图纸所作的任何更改，以及可由工程师随时提供或书面认同的其他图纸。

（m）“Site” means the land and other places on，under，in or through which the Permanent Works or Temporary Works designed by the Engineer are to be executed and any other lands and places provided by the Employer for working space or any other purpose as may be apecifically designated in the Contract as forming part of the Site．

“工地”指工程师设计的永久性或临建工程施工所需的土地及其他场地，包括地面、地下、在之上或通过部分，以及由业主所提供的用作临时储存或其他目的的其他土地或场所，只要能按合同明文规定构成工地的组成部分。

（n）“Approved” means approved in wri ting，including subsequent written

confirmation ofprevious verbalapproval and“approval' means approval in writing，including as aforesaid．

“业经认可”指已经经书面认可，包括过后对口头认可的书面确认，“认可”指书面认可，包括上述规定在内。

（2）Words importing the singular only also include the plural and vice versa where the context requires?

1．2按合同上下文所需，单数含义的单词也可具有复数的含义，反之一样。

（3）The headings and marginal notes in these Conditions of Contract shall not be deemed to be part thereof or be taken into consideration in the interpretation or construction thereof or of the Contract．

1．3合同条款的标题和边注不得视为合同的一部分，不得用于考虑解释条款或合同。

（4）The word“cost' shall be deemed to include overhead costs whether on or off the Site．

1．4“费用”一词应视为含工地上或以外发生的间接费用。

ENGINEER AND ENGINEER’S REP RF．SFNTATIVE

工程师及工程师代表

2．（1）The Engineer shall carry out such duties in issuing decisions，certificates and orders as are specified in the Contract．In the event of the Engineer being required in terms of his appointment by the Employer to obtain the specific approval of the Employer for the execution of any part of these duties，this shall be set out in Part II of these Conditions．

2．1工程师必须按合同明文规定，履行作决断、颁发证书和发出指令等职责。如业主签发的工程师任命书中规定其某些职责的履行得经业主专门认可，其要件应在本合同第二部

分予以规定。

（2）The Engineer may from time to time in writing delegate to the Engineer's Representative any of the powers and authorities vested in the Engineer and shall furnish to the Contractor and to the Employer a copy of all such written delegations of powers and authorities．Any written instruction or approval given by the Engineer’s Representative to the Contractor within the terms of such delegation，but not otherwise，shall bind the Contractor and the Employer as though it had been given by the Engineer．Provided always as follws：

2．2工程师可随时书面授权其代表代行其任何职权，但必须将所有此种授权书的副本提交给承包人和业主。在授权期间，工程师代表给承包人的任何书面指令或认可（仅限于此）对承包人和业主具有与工程师的指令或认可同样的效力。以下规定属于例外：

（a） Failure of the Engineer's Representative to disapprove any work or materials shall not prejudice the power of the Engineer thereafter to disapprove such work or materials and to order the pulling down，removal or breaking up thereof．

工程师代表对任何工程或材料的不予否认，不得影响工程师此后否认以及命令拆毁、移动或拆除此种工程或材料的权力。

（b）If the Contractor shall be dissatisfied by reason of any decisions of the Engineer's Representative he shall be entitled to refer the matter to the Engineer，who shall thereupon confirm，reverse or vary such decision．

若承包人对工程师代表的任何决定不满意，其有权将此决定提交工程师确认、取消或更改。

ASSIGNMENT AND SUB—LETTING

转让和分包

3．The Contractor shall not assign the Contract or any part thereof，or any benefit or interest therein or thereunder，otherwise than by a charge in favor of the Contractor's bankers of any monies due or to become due under this Contract，without the prior written consent of the Employer．

3．未经业主事前书面同意，承包人不得将合同或其他任何部分，或合同所规定或依合同而产生的任何收益转让，向承包人的开户银行支付按本合同规定到期或即将到期的款项除外。

4．The Contractor shall not sub-let the whole of the Works．Except where otherwise provided by the Contract，the Contractor shall not sub-let any part of the Works without the prior written consent of the Engineer，which shall not be unreasonably withheld，and such consent，if given，shall not relieve the（contractor from any liability or obligation under the Contract and he shall be responsible for the acts，defaults and neglects of any sub-contractor，his agents，servants or workmen as fully as if they were the acts，defaults or neglects of the Contractor，his agents． servants or workmen．Provided always that the provision of labor on a piecework basis shall not be deemed to be a subletting under the Clause．

4．承包人不得转包整个工程。除非合同另有规定，未经工程师事前书面同意，承包人也不得分包工程的任何部分，但工程师不得无故不同意分包，一旦同意分包，此种同意不得免去承包人所承担的任何合同所规定的责任或义务，他必须对任何分包人、其代理人、雇员或工人的行为、不履行和过失负完全责任，如同这些行为、不履行或过失是承包人、其代理人、雇员或工人所为。以计件方式提供劳力不得视为是本条所规定的分包。

CONTRACT DOCUMENTS

合同文件

5．（1）There shall be stated in Part 1I of these Conditions：

5．1以下要件得在合同第二部分规定：

（a）the language or languages in which the Contract documents shall be drawn up and．

用以起草合同文件的语言；

（b）the country or state，the law of which is to apply to the Contract and according to which

the Contract is to be construed．

合同适用哪个国家的法律以及用哪个国家的法律解释合同。

If the said documents are written in more than one language，the language according to which the Contract is to be construed and interpreted shall also be designated in Part II，being therein designated the “Ruling Language”．

如果文件用一种以上语言作成，用以解释合同的语言也必须在第二部分中规定，且将被寇为“主体语言”。

（2）Except if and to the extent otherwise provided by the Contract，the provisions of the Conditions of Contract Parts Ⅰ and Ⅱshall prevail over those of any other document forming part of the Contract．Subject to the foregoing，the several documents forming the Contract are to be taken as mutually explanatory of one another，but in case of ambiguities or discrepancies the same shall be explained and adjusted by the Engineer who shall thereupon issue to the Contractor instructions thereon．Provided always that if，in the opinion of the Engineer，compliance with any such instructions shall involve the Contractor in any cost，which by reason of any such ambiguity or discrepancy could not reasonably have been foreseen by the Contractor，the Engineer shall certify and the Employer shall pay such additional sum as may be reasonable to cover such costs．

5．2除合同中另有规定外，合同第一、二部分的条款规定优于其他任何构成合同的文件的规定。以上述规定为准，构成合同的数个文件可视为能互相解释，如意思含糊或不一致时，由工程师解释和处理，并由此向承包人发出指令。如工程师认为，服从此种指令会使承包人发生额外费用，而此种费用是承包人由于上述意思含糊或不一致而按理无法预见的，工程师应予以证明，业主必须支付相应的额外款额以补偿此种费用。

6．（1）The Drawings shall remain in the sole custody of the Engineer，but two copies thereof shall be furnished to the Contractor free of charge．The Contractor shall provide and make at his own expense any further copies required by him．At the completion of the Contract the Contractor shall return to the Engineer all

Drawings provided under the Contract．

6．1图纸由工程师独自保管，但须向承包人免费提供两份副本。承包人所需的其余副本由他自己制作并承担费用。合同履行后，承包人须将全部合同图纸归还工程师。

（2）One copy of the Drawings，furnished to the Contractor as aforesaid，shall be kept by the contractor on the Site and the same shall at all reasonable times be available for inspection and use by the Engineer and the Engineer's Representative and by any other person authorized by the Engineer in writing．

6．2承包人必须将按上述规定所提交的一份图纸副本留在工地，让工程师及其代表，或工程师书面授权的任何其他人在所有合理的时间内查阅使用。

（3）The Contractor shall give written notice to the Engineer whenever planning or progress of the Works' is likely to be delayed or disrupted unless any further drawing or order，including a direction，instruction or approval，is issued by the Engineer within a reasonable time．The notice shall include details of the drawing or order required and of why and by when it is required and of any delay or disruption likely to be suffered if it is late．

6．3如工程师不在适当时间内再提供图纸或命令，包括指示、指令或认可，工程计划或进展便可能被延误或中断时，承包人必须书面通知工程师。通知书中应详细说明所需的图纸或命令，所需原因和时间，以及如果不及时提供而可能造成的任何延误和中断。

（4）If，by reason of any failure or inability of the Engineer to issue within a time reasonable in all the circumstances any drawing or order requested by the Contractor in accordance with subclause（3）of this Clause，the Contractor suffers delay and/or incurs costs then the Engineer shall take such delay into account in determining any extension of time to which the Contractor is entitled under Clause 44 hereof and the Contractor shall be paid the amount of such cost as shall be reasonable．

6．4如承包人按本条第3款规定索要图纸或命令，由于工程师没有或不能在合理时间内

提供，从而导致承包人误工和左戊承担费用，工程师必须考虑此种延误，以决定是否按本合

同第44条规定延长承包人的工期，且只要有理由，承包人所承担的此种费用必须得到补偿。

7．The Engineer shall have full power and authority to supply to the Contractor from time to time, during the progress of the Works，such further drawings and instructions as shall be necessary for the purpose of the proper and adequate execution and maintenance of the Works． The Contractor shall carry out and be bound by the same．

7．在施工期间，工程师全权负责随时进一步向承包人提供图纸和指示，以满足工程正常施工和维护所需。承包人必须执行且受图纸和指示的约束。

GENERAL OBLIGATIONS

总义务

8．（1）The Contractor shall，subject to the provisions of the Contract，and with due care and diligence, execute and maintain the Works and provide all labor，including the supervision thereof, materials，Constructional Plant and all other things，whether of a temporary or permanent nature，required in and for such execution and maintenance，so far as the necessity for providing the same is specified in or is reasonably to be inferred from the Contract．

8．1承包人必须根据合同条款，对工程的施工和维护予以应有的注意，且提供此种施工和维护所必需的包括劳动管理在内的所有劳力、材料、施工成套设备及其他一切物品，不管其是临时或长期性质，只要合同明文规定需要或根据合同合理推断需要。

（2）The Contractor shall take full responsibility for the adequacy，stability and safety of all site operations and methods of construction，provided that the Contractor shall not be responsible, except as may be expressly provided in the Contract，for the design or specification of the Permanent Works，or for the design or specification of any Temporary Works prepared by the Engineer?

8．2承包人必须对现场操作和施工方法的恰当、稳定及安全性负全部责任。除非合同另有明文规定，承包人对工程师制定的永久性工程的设计或规格，或临建工程的设计或规格

概不负责。

9．The Contractor shall，when called upon so to do，enter into and execute a Contract Agreement，to be prepared and completed at the cost of the Employer，in the form annexed with such modification as may be necessary，

9．如经要求，承包人必须签署一承包协议，该协议由业主制定并承担费用，协议应附带必要的修正条款。

10．If，for the due performance of the Contract，the Tender shall contain an undertaking by

the Contractor to obtain，when required，a bond or guarantee of an insurance company or bank, or other approved sureties to be jointly and severally bound with the contractor to the Employer, in a sum not exceeding that stated in the Letter of Acceptance for such bond or guarantee，the said insurance company or bank or sureties and the terms of the said bond or guarantee shall be such as shall be approved by the Employer． The obtaining of such bond or guarantee or theprovision of such sureties and the cost of the bond or guarantee to be so entered into shall be at the expense in all respects of the Contractor，unless the Contract otherwise provides．

10．为正常履行合同，在标书中，承包人应承诺按要求取得保险公司或银行的保单或保函，或其他业经认可由承包人向业主负连带责任的担保，其数额不超过验收证书中规定的保单或保函额，上述保险公司、银行或担保以及上述保单或保函的条款必须经业主认可。此种保单或保函的取得或担保的提供，以及缔结保单或保函的费用应全部由承包人承担，合同中另有规定的除外。

11．The Employer shall have made available to the Contractor with the Tender documents such data on hydrological and sub-surface conditions as shall have been obtained by or on behalf of the Employer from investigations undertaken relevant to the Works and the Tender shall be deemed to have been based on such data，but the Contractor shall be responsible for his own interpretation thereof．

11．业主必须在招标文件中向承包人提供由业主或其代理人在进行工程考察时获得的水文及地质情况资料，标书必须视为是基于此种资料所制定的，但承包人必须对资料的理解自行负责。

The Contractor shall also be deemed to have inspected and examined the Site and its surroundings and information available in connection therewith and to have satisfied himself，so far as is practicable，before submitting his Tender，as to the form and nature thereof，including the sub-surface conditions，the hydrological and climatic conditions，the extent and nature of work and materials necessary for the completion of the Works，the means of access to the site and the accommodation he may require and，in general，shall be deemed to have obtained all necessary information，subject as above mentioned，as to risks，contingencies and all other circumstances which may influence of affect his Tender．

承包人也必须被视为已视察了工地及周围环境，查阅了可获得的有关工地资料，且在提交标书前，对一切实际情况，从形式到性质，包括地质条件、水文和气候条件、工程范围和性质以及完成工程所必需的材料、到达工地的交通工具和所需的食宿等感到满意，总之，承包人必须被视为已得到所有必要的资料，除涉及上述情况外，还涉及风险、意外事件及其他一切可能影响其投标的情况。

12．The Contractor shall be deemed to have satisfied himself before tendering as to the correctness and sufficiency of his Tender for the Works and of the rates and prices stated in the priced Bill of Quantities and the Schedule of Rates and Prices，if any，which Tender rates and prices shall，except insofar as it is otherwise provided in the Contract，cover all his obligations under the Contract and all matters and things necessary for the proper execution and maintenance of the Works．if，however，during the execution of the Works the Contractor shall encounter physical conditions，other than climatic conditions on the Site，or artificial obstructions，which conditions or obstructions could，in his opinion，not have been reasonably foreseen by an experienced contractor，the Contractor shall forthwith give written notice thereof to the Engineer's Representative and if，in the opinion of the Engineer，such conditions or artificial obstructions could not have been reasonably foreseen by an experienced contractor，then the Engineer shall certify and the Employer shall pay the additional cost to which the Contractor shallhave been put by reason of such conditions，including the proper and reasonable cost．

12．承包人得被视为在投标前已对其工程标书，对标价的建筑工程清单、单价和价格表（如果有）上所列的单价和价格的正确性和完善性感到满意，此种投标价格必须贯穿其所有的合同义务，适用于所有为工程的正常施工和维护所必需的事物，除非本合同另有规定。然

而，在施工期间，如承包人遇到除工地气候之外的其他自然情况或人为阻碍，依他所见，此种自然情况或人为阻碍是经验丰富的承包人也无法预见的，承包人必须立即书面通知工程师代表，如工程师确认此种情况或人为阻碍为经验丰富的承包人无法合理预见，工程师必须作证且业主支付承包人由于此种情况而承担的额外费用，包括因遇到此种情况或阻碍而：

（a）of complying with any instruction which the Engineer may issue to the Contractor in connection therewith，and

（1）为执行工程师可能向承包人发出的与此情况有关的任何指示而发生的正当合理的费用，以及

（b）of any proper and reasonable measures approved by the Engineer which the Contractor may take in the absence of specific instructions from the Engineer．as a result of such conditions or obstructions being encountered．

（2）在无工程师具体指示时，承包人可能采取业经工程师认可的恰当和合理措施而发生的正当合理费用。

13．Save insofar as it is legally or physically impossible，the Contractor shall execute and maintain the Works in strict accordance with the Contract to the satisfaction of the Engineer and shall comply with and adhere strictly to the Engineer's instructions and directions on any matter whether mentioned in the Contract or not，touching or concerning the Works．The Contractor shall take instructions and directions only from the Engineer or，subject to the limitations referred to in Clause 2 hereof，from the Engineer's Representative．

13．除因法律或自然因素而不能之外，承包人必须严格按合同规定施工和维护工程，使工程师感到满意，且必须遵守和严格执行工程师有关任何事项的指令和指示，不管合同中是否有规定，提及或涉及到工程，承包人只能从工程师处接受指令和指示，或根据本合同第2条规定，接受工程师代表的指令和指示。

14．（1）Within the time stated in Part 11 of these Conditions，the Contractor shall，after the acceptance of his Tender，submit to the Engineer for his approval a program showing the order of procedure in which he proposes to carry out the Works．The Contractor shall，whenever required by the Engineer or Engineers’Representative，also provide in writing for his information a general

description of the arrangements and methods which the Contractor proposes to adopt for the execution of the Works．

14．1中标后，承包人得在第二部分条款规定的时间内向工程师提交一份其计划施工的程序方案，以征得工程师的认可。承包人还得随时应工程师或其代表的要求，提供一份承包人的施工计划安排和方法的说明书，以供其参考。

（2）If at any time it should appear to the Engineer that the actual progress of the Works does not conform to the approved program referred to in sub-clause （1）of this Clause，the Contractorshall produce，at the request of the Engineer，a revised program showing the modifications to the approved program necessary to ensure completion of the Works within the time for completion asdefined in Clause 48 hereof．

14．2不论何时，只要工程师发现工程实际进度与本条第1款规定的业经认可的方案不符，承包人必须应工程师的要求，提供一份修改方案，对原有的方案作必要的修正，以保证工程能在本合同第48条规定的期限内完工。

（3）The submission to and approval by the Engineer or Engineer's Representative of such programs of the furnishing of such particulars shall not relieve the Contractor of any of his duties or responsibilities under the Contract．

14．3承包人不得因向工程师或工程师代表提交或经其认可此种方案或因提供此种细节，而被免除任何合同责任或义务。

15．The Contractor shall give or provide all necessary super- intendance during the execution of the Works and as long thereafter as the Engineer may consider necessary for the proper fulfilling of the Contractor's obligations under the Contract．The Contractor，or a competent and authorized agent or representative approved of in writing by the Engineer，which approval may at any time be withdrawn，is to be constantly on the Works and shall give his whole time to the super-intendance of the same．If such approval shall be withdrawn by the Engineer，the Contractor shall，as soon as is practicable，having regard to the requirement of replacing him as hereinafter mentioned，after receiving written noticeof suchwithdrawal，remove the agent from the Works and shall not thereafter employ him again on the Works in any capacity and shall replace him by another agent approved by the Engineer．Such

authorized agent or representative shall receive，on behalf ofthe Contractor，directions and instructions from the Engineer or， subject to the limitations of Clause 2 hereof，the Engineer's Representative．

15．在施工期间，以及其后在工程师认为是为正常履行合同义务而必需时，承包人必须行使一切监督权。承包人，或其经工程师书面认可的全权代理人或代表（此种认可可随时撤销）应当随时在工地，一直进行监督管理。如工程师撤销对代理人的认可，在接到书面撤销通知后，承包人必须尽快根据撤换规定，将其撤离工地，且今后不得再在工地上以任何身份雇佣他（她），且用另外一位经工程师认可的代理人予以替代。此种授权代理人或代表得代表承包人接受工程师的指令和指示，或按本合同第2条规定，接受工程师代表的指令和指示。

16．（1）The Contractor shall provide and employ on the Site in connection with the execution and maintenance of the Works．

16．1承包人必须在工地上提供和雇用与施工和工程维护有关的：

（a） only such technical assistants as are skilled and experienced in their respective callings and such sub-agents，foremen and leading hands as are competent to give proper supervision to the work they are required to supervise，and

（1）对本专业熟悉和经验丰富的技术人员，能胜任规定监管工作的分代理人、工头和领班，以及

（b）such skilled，semi-skilled and unskilled labor as is necessary for the proper and timely execution and maintenance of the Works．

（2）为正常和及时施工和维护工程所需的熟练、半熟练和非熟练工人。

（2）The Engineer shall be at liberty to object to and require the Contractor to remove forthwith from the Works any person employed by the Contractor in or about the execution ormaintenance of the Works who，in the opinion of the Engineer，misconducts himself，or is incompetent or negligent in the proper performance of his duties，or whose employment is otherwise considered by the Engineer to be undesirable and such person shall not be again employed upon the Works without the written permission of the Engineer．Any person so removed from the Works shall be replaced as soon as possible by a competent substitute approved by the Engineer．

16．2如工程师认为承包人雇来进行或有关施工或工程维护的任何人员行为不轨、或不能或疏于履行其职责、或认为其雇佣纯属不必要，工程师有权反对雇佣，并要求承包人立即将其从工地解雇，未经工程师的书面同意，此种人员不得再被雇用到工地。凡被从工地解雇人员的职位应尽快由工程师认可的称职人选接替。

17．The Contractor shall be responsible for the true and proper setting-out of the Works in relation to original points，lines and levels of reference given by the Engineer in writing and for the correctness，subject as above mentioned，of the position，levels，dimensions and alignment of all parts of the Works and for the provision of all necessary instruments，appliances and labor in connection therewith．If，at any time during the progress of the Works，any error shall appear or arise in the position，levels，dimensions or alignment of any part of the Works，the Contractor， on being required so to do by the Engineer or the Engineer's Representative，shall，at his own cost，rectify such error to the satisfaction of the Engineer or the Engineer's Representative，unless such error is based on incorrect data supplied in writing by the Engineer or the Engineer's Representative，in which case the expense of rectifying the same shall be borne by the Employer． The checking of any setting-out or of any line or level by the Engineer or the Engineer's Representative shall not in any way relieve the Contractor of his responsibility for the correctness thereof and the Contractor shall carefully protect and preserve all bench-marks， sight-rails，pegs and other things used in setting-out the Works．

17．承包人负责按工程师提交的书面参考原图的有关点、线和面的规定，忠实恰当地进行测定放线，如上所述，使工程的位置、水平、面积正确无误，并校准工程的各部分，且负责提供与工程相关的所有必要工具、设备和劳力。在施工中，如任何时候在工程的位置、水平、面积或工程任何部分的校正出现差错，应工程师或工程师代表的要求，承包人必须改正错误以使工程师或工程师代表满意，改正费用由承包人自己承担，此种错误是由工程师或工程师代表提供的书面资料差错而导致的除外，在这种情况下，须由业主承担改正费用。承包人不得因工程师或工程师代表对任何位置测定或任何线或任何水平面的检查而免去确保其正确无误的责任，承包人必须仔细保护和保存工程位置测定中使用过的水准点、观测杆、测标及其他物品。

18．If，at any time during the execution of the Works，the Engineer shall require the Contractor to make bore holes or to carry out exploratory excavation，such requirement shall be ordered in writing and shall be deemed to be an addition ordered

under the provisions of Clause 51 hereof，unless a provisional sum in respect of such anticipated work shall have been included in the Bill of Quantities．

18．在施工中，工程师如在任何时间要求承包人钻孔或进行挖掘勘探，此种要求必须作成书面形式，且得视为是根据本合同第51条规定作出的附加命令，除非数量清单中已经列有有关此种预计工程的备用款。

19．The Contractor shall in connection with the Works provide and maintain at his own cost all lights，guards，fencing and watching when and where necessary or required by the Engineer or the Engineer's Representative，or by any duly constituted authority， for the protection of the Works，or for the safety and convenience of the public or others．

19．凡有必要或应工程师或工程师代表、或任何正式成立的工程管理处的要求，承包人必须自费提供和维护与工程有关的所有灯光、警卫、栅栏和看护以保卫工程，或保障公众及其他人的安全和便利。

（1）From the commencement of the Works until the date stated in the Certificate 20．

of completion for the whole of the Works pursuant to Clause 48 hereof the Contractor shall take full responsibility for the care thereof．Provided that if the Engineer shall issue a Certificate of Completion in respect of any part of the Permanent Works the Contractor shall cease to be liable for the care of that part of the Permanent Works from the date stated in the Certificate of Completion in respect of that part and the responsibility for the care of that part shall pass to the Employer． Provided further that the Contractor shall take full responsibility for the care of any outstanding work which he shall have undertaken to finish during the Period of Maintenance until such outstanding work is completed．In case any damage，loss or injury shall happen to the Works，or to any part thereof，from any cause whatsoever，save and except the excepted risks as defined in subclause（2）of this Clause，while the Contractor shall be responsible for the care thereof the Contractor shall，at his own cost，repair and make good the same，so that at completion the Permanent Works shall be in good order and condition and in conformity in every respect with the requirements of the Contract and the Engineer's instructions．In the event of any such damage loss or injury happening from any of the excepted risks，the Contractor shall，if and to the extent required by the Engineer and subject always to the provisions of Clause 65 hereof， repair and make good the same as aforesaid

at the cost of the Employer．The Contractor shall also be liable for any damage to the Works occasioned by him in the course of any operations carried out by him for the purpose of completing any outstanding work or complying with his obligations under Clauses 49 or 50 hereof．

20．1从开工至按本合同第48条中的竣工证书规定的日期为止，承包人都得对工程全权负责。只要工程师就永久性工程的任何部分签发了竣工证书，承包人从部分竣工证书中规定的日期起不再对永久性工程的此部分负责，此部分的责任则转至业主。此外，承包人必须对任何尚未完工而他得在维护期内完成的工程负全权维护，直至此种工程完工。如工程或其任何部分出现任何损害、损失或毁坏，不论何种原因，除本条第2款规定的除外风险外，承包人均得自费负责修理和修补，以确保永久性工程竣工时处于状态良好，各方面都合乎合同的要求和工程师的指示。如因除外风险而导致任何损害、损失或毁坏发生，承包人必须应工程师的要求（如果有）以及本合同第65条的规定，如上所述，进行修理和修补，费用由业主承担。承包人也必须对为完成未竣工程或履行本合同第49或50条规定的义务，在施工过程中对工程造成的任何损害负责。

（2）“The excepted ris ks' are war，hostilities（whether war be declared or not），invasion act of foreign enemies，rebellion，revolution，insurrection or military or usurped power，civil war，or unless solely restricted to employees of the Contractor or of his sub-contractors and arisingfrom the conduct of the Works，riot，commotion or disorder，or use or occupation by the Employer of any part of the Permanent Works，or a cause solely due to the Engineer's design of the Works，or ionizing radiation，or contamination by radio-activity from any nuclear fuel or from any nuclear waste from the combustion of nuclear fuel，radio-active toxic explosive，or other hazardous properties of any explosive，nuclear assembly or nuclear component thereof，pressure waves caused by aircraft or other aerial devices travelling at sonic or supersonic speeds，or any such operation of the forces of nature as an experienced contractor could not foresee，or reasonably -make provision for or insure against all of which are herein collectively referred to as“the excepted risks'．

20．2“除外风险”包括战争、敌对状态（无论是否宣战）、侵略、外国敌人行为、叛乱、革命、起义或兵变或篡权、内战、或不是由承包商的雇员、其转包人单独制造和不是因工程管理而发生的暴动、骚乱或混乱、或因业主使用或占用任何部分的永久性工程、或纯属工程师工程设计的原因、或因任何核燃料或核燃料燃烧后的废料以及放射性有毒爆炸物引起的辐射和污染、或任何爆炸物、核装置或核装置部件的其他危险特性、以音速、超音速飞行

的飞机或其他飞行物的压力波以及其他任何此种自然力的作用，其不能为有经验的承包商所预见，也不能合理提供物资或投保与之对抗，所有这一切在本合同中都被称为“除外风险”。

21．Without limiting his obligations and responsibilities under Clause 20 hereof，the Contractor shall insure in the joint names of the Employer and the Contractor against all loss or damage from whatever cause arising，other than the excepted risks，for which he is responsible under the terms of the Contract and in such manner that the Employer and Contractor are covered for the period stipulated in Clause 20（1）hereof and are also covered during the Period of Maintenance for loss or damage arising from a cause，occurring prior to the commencement of the Period of Maintenance，and for any loss or damage occasioned by the Contractor in the course of any operations carried out by him for the purpose of complying with his obligations under Clauses 49 and 50 hereof；

21．承包人必须以业主和承包人的共同名义，为防止合同规定的应由承包人负责的、除外风险外的一切损失或损害投保，不论其由什么原因造成，此种投保不得减少本合同第20条所规定的承包人的义务和责任，业主和承包人的保险除包括本合同第20．1条规定的期限外，还包括因维护期开始前发生的原因而在维护期内产生的损失或损害，以及承包人在履行本合同第49或50条规定的义务而开展任何工作期间所造成的任何损失或损害。投保项目包括：

（a）The Works for the time being executed to the estimated current contract value thereof，or such additional sum as may be specified in Part 11 in the Clause numbered 21，together with the materials for incorporation in the works at their replacement value．

（1）正在施工的工程，按其目前的合同价值，或按21条第2款可能规定的附加款额，连同按替换价值计算的用于工程的材料。

（b）The Constructional Plant and other things brought on to thethe replacement value of such Constructional Plant and other things．

（2）承包商带到工地上的建筑成套设备和其他物品，按其替换价值投保。

Such insurance shall be effected with an insurer and in terms apwhich approval shall not be unreasonably withheld, and the Contractor shall , whenever required ,

produce to the Engineer or the Engineer's Representative the policy or policies of insurance and the receipts for payment of the current premiums．

此种保险必须在一保险公司投放，条款得经业主认可，业主不得无故不同意投保，承包人必须随时应要求向工程师或工程师代表出示保险单和支付现行保险费的收据。

22．（1）The Contractor shall，except if and so far as the Contract provides otherwise，indemnify the Employer against all losses and claims in respect of injuries or damage to any person or material or physical damage to any property whatsoever which may arise out of or in consequence of the execution and maintenance of the Works and against all claims，proceedings，damages，costs，charges and expenses whatsoever in respect of or in relation thereto except any compensation or damages for or with respect to：

22．1除合同另有规定外，承包人必须保护业主不得因施工和工程维护而产生或导致的任何人员伤害、材料损失及财产损失而受任何损失和作任何赔偿，且不因所有与之有关的任何索赔、诉讼、损害赔偿金、诉讼费、开支和费用而受损失，对下列事项所作或与之有关的补偿或损害赔偿除外：

（a）The permanent use or occupation of land by the Works or any part thereof．

工程或部分工程永久使用或占用土地；

（b）The right of the Employer to execute the Works or any part thereof on，over，under in or through any land．

业主在任何土地面上、上方、下面、里面或经过部分施工或部分施工的权利；

（c）Injuries or damage to persons or property which are the unavoidable result of the execution or maintenance of the Works in accordance with the Contract．

按合同规定施工或维护工程而不可避免的人身伤害或财产损失；

（d）Injuries or damage to persons or property resulting from any act or neglect of the Employer，his agents，servants or other contractors，not being employed by the Contractor，or for or in respect of any claims，proceedings，damages，costs，

charges and expenses in respect thereof or in relation thereto or where the injury or damage was contributed to by the Contractor， his servants or agents such part of the compensation as may be just and equitable having regard to the extent of the responsibility of the Employer，his servants or agents or other contractors for the damage or injury．

因业主、其代理人、雇员或其他不为承包人所雇用的承包商的任何行为或过失所造成的人员伤害或财产损失，或与之有关的任何索赔、诉讼、损害赔偿金、诉讼费、开支和费用，或曾由承包人、其雇员或代理人承担的，但原本应当由业主、其雇员或代理人或其他承包商负责的那部分涉及损失或伤害的赔偿。

（2）The Employer shall indemnify the Contractor against all claims，proceedings，damages，costs, charges and expenses in respect of the matters referred to in the provision sub-clause （1）of this Clause．

22．2业主必须保护承包人不因与本条第1款规定事项有关的一切索赔、诉讼、损害赔偿金、诉讼费、开支和费用而受损失。

23．（1）Before commencing the execution of the Works the Contractor，but without limiting

his obligations and responsibilities under Clause 22 hereof，shall insure against his liability for anymaterial or physical damage，loss or injury which may occur to any property，including that of the Employer，or to any person，including any employee of the Employer，by or arising out of the

execution of the Works or in the carrying out of the Contract，otherwise than due to the matters referred to in the provision Clause 22（1）hereof．

23．1在开工前，在不减少本合同第22条规定给他的义务和责任条件下，承包人必须对任何可能由于或因施工或因履行本合同而给包括业主的财产在内的任何财产，以及给包括业主的雇员在内的任何人员造成的重大或实质性损害、损失或伤害进行责任保险，本合同第22条规定的事项除外。

（2）Such insurance shall be effected with an insurer and in terms approved by the Employer，which approval shall not be unreasonably withheld，and for at least

非全日制建筑与土木工程

昆明理工大学 非全日制硕士专业学位研究 生培养方案 ????专业学位名称工程硕士 ?????专业学位领域名称建筑与土木工程 ?????研究生部 制定日期：2011年10月20日

一、专业领域简介 本学科领域紧密结合省情和经济建设需要，坚持理论与实践相结合的发展模式，在大的方向上分为土木工程方向、建筑学方向、工程管理方向。 土木工程方向围绕工程结构（包括钢结构、空间结构、混凝土结构、组合结构、桥隧结构等）基础理论及工程应用、结构安全评价与健康诊断、防灾减灾、工程抗震、岩土工程治理技术、地基基础工程、新型建材、施工技术、市政建筑设施等方面开展全面、系统的研究。 建筑学方向结合地方经济、社会发展需要和城镇人居环境、城乡建设发展、以及全国注册建筑师行业制度，从理论与实践上重点对建筑、城市进行整体、全面、深入的探讨与设计实践。本学位点以建筑设计和城市设计实践为主，致力于研究古今中外建筑的相关理论与设计方法；研究建筑设计和城市设计发展趋势的一般规律，研究城市及其区域发展变化及其对人类活动影响的规律；研究建筑遗产保护等相关技术问题。 工程管理方向以工程实践为导向，重视实践和应用，适应工程建设领域实际工作需要的应用型高层次专门人才。教育的突出特点是学术性与职业性紧密结合，课程学习以理工结合、经济、管理与法规融于一体。 Introduction to Architecture and civil Engineering This research field combines with the Y unnan province affection and the needs of economic construction, insisting to th e combination of theory and practice. In total, it can be divided into three research direction, engineering, architecture, and project management. The engineering research direction focuses on the construction structure (including steel structure, spatial structure, concrete structure, composite structure, bridge and tunnel structure, and so on) theory and application in engineering, structural safety evaluation and health diagnosis, disaster prevention and mitigation engineering, engineering seismology, geotechnical engineering management technique, foundation engineering, new building materials, modern construction technology and pt, municipal engineering, and so on. The architecture research direction combines with local economy, social development need and environment of human settlements, vernacular villages, the local features and characteristics of architectural culture, this major takes emphasis on integral, comprehensive and deep design practices from single building to whole city in the light of the National Registered A rchitects’ industry system. Besides that this major makes studies on design methods and related theory of traditional and modern architecture both in China and foreign countries, on universal laws of

建设工程内部承包合同书(标准版).docx

LOGO 建设工程内部承包合同书WORD模板文档中文字均可以自行修改 ××××有限公司

编号：_____________建设工程内部承包合同书 甲方：___________________________ 乙方：___________________________ 签订日期：_______年______月______日

总包方： (以下简称甲方） 承包方：（身份证号：）（以下简称乙方） 为强化企业管理，提高企业经济效益，调动项目经理的工作积极性，确保甲方与建设单位签订的《建设工程施工合同》中的各项经济与责任条款的全面履行，依照《合同法》、《建筑法》的原则。甲方将________________工程的施工任务交给乙方，代表公司处理并承担质量、进度、安全等技术及经济责任，为明确甲、乙双方的职责，结合本工程具体情况，经双方商议达成以下协议条款，以资共同遵守 工程概况 1.1工程名称： 1.2结构层次： 1.3建筑面积： 1.4工程地点： 第二条工程承包范围和形式 2.1工程范围：甲方与建设单位所签订合同的工程量、施工图纸范围内所有工程量 2.2承包形式：包工包料、包工期、包质量、包安全、包造价。乙方按建设工程标准、甲方管理要求施工，实行单项核算，自负盈亏。

第三条工程工期 3.1施工工期：年月日至年月日。（工期提前或推迟的奖罚按甲方与建设单位签订的建设工程施工合同书中的有关条款执行） 3.2如设计有重大变更、建设方缓建或停建、人力不可抗拒的自然灾害因素影响时，经建设方签证工期顺延。 第四条工程造价及价款的支付和结算 4.1工程造价暂按合同价（人民币大写）：，总价以工程竣工验收合格后甲方与建设单位决算的工程总造价为准。 4.2甲、乙双方商定甲方按工程决算总价的收取管理费。此费用包括甲方按国家和地方的法律标准应当缴纳的一切税、费，以及甲方对乙方进行的管理费、规费等费用。 4.3由甲方从分期到帐的工程款中将管理费用按比例预扣。 第五条甲、乙双方责任 5.1甲方的责任： ⑴、负责驻地施工注册，配合乙方做好驻地施工区域与建设单位、行政主管部门的协调工作，为乙方对本工程的承包和顺利施工提供必要的有关证件和手续。向建设单位收取工程备料款、进度款，并在扣除有关款项后及时划拨至乙方，负责财务监督和总拨款控制，确保乙方工程款的专款专用。 （2）甲方应当组建施工工程的现场管理班子，为乙方提供施工现场的管理人员和技术人员，审批核定乙方编制的施工组织设计（或施工

中英文建筑工程合同(ContractofConstructionProject)

编号：_______________ 本资料为word版本，可以直接编辑和打印，感谢您的下载 中英文建筑工程合同 (ContractofConstructionProject) 甲方：___________________ 乙方：___________________ 日期：___________________

Contract of Construction Project 合同编号：Contract Number: 工程名称：Project Name: 发包方(甲方)： ______________________________ Employer (Party A): ________________________ 承包方(乙方)： ______________________________ Contractor (Party B): ________________________ 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1 .工程地点：Project site: 2. 工程范围：Scope of project 3. 工程造价：人民币元整(该造价为包工包料价) Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials) 第二条施工准备Article 2, Preparation for construction 1 .甲方协助乙方办理临时水电及垂直运输，提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2 .乙方：.Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. ②组织施工管理人员和材料、施工机械进场；

室内设计中英文对照

常用室内设计词汇-中英文对照 室内设计-interior design 室内设计师- interior designer 建筑-architecture 建筑师-architect 景观-landscape 家具-furniture 灯光-lighting 照明-illumination 家居设计-residential design 商业设计-commercial design 软装-FF&E（furniture fixture and equipment) 人体工程学-ergonomics 空间-space 精品酒店-boutique hotel 草图-draft or sketch 规格-specification 汇报或讲解-presentation 渲染或着色-rendering 透视-perspective 规范-code 对称-symmetry 不对称-asymmetry 轴线-axis 空间篇 住宅类 客厅，起居室—living room 餐厅-dinning room 玄关-foyer 卧室-bedroom 主卧-master bedroom 次卧-second bedroom 客卧-guest bedroom 厨房-Kitchen 厨岛kitchen island 书房-study room 衣帽间-cloakroom 卫生间-bathroom , toilet , bath 储藏室-storage 楼梯-stair 阳台-balcony 花园-garden 露台-patio 商业类 1办公类 接待处- reception 候客区-waiting Area or lounge 会议室（小型的）-meeting room or seminar 会议室（大型的）-conference room 办公室- office 经理办公室manager office 开放式的工作区-work area 多功能室-multi-function room 2酒店类 入口-entrance 出口-exit 大堂-lobby 前厅-vestibule 过道-corridor 休闲区,等候区-lounge 宴会厅-ballroom 客房-guestroom 套间-suite 行政套房-executive suite 总统套房-presidential suite 健身中心—fitness center or gym 瑜伽-yoga 泳池-swimming pool Spa 咖啡厅-cafe 酒吧-bar 餐厅-restaurant 备餐-pantry 电梯-elevation or lift 卫生间-restroom 男-men's 女women's 影院-cinema 商务中心-business center 行李间-luggage store 盥洗室-lavatory 3其他类 天花-ceiling 长廊-pavilion 零售店-retail store 大厅(堂）-hall 展览-gallery

国际建筑工程承包合同(2021)

YOUR LOGO 国际建筑工程承包合同(2021) The contract is the guarantee for both parties, safeguarding the legitimate rights and interests of both parties, and binding both parties to perform their responsibilities and obligations. 专业合同系列，下载即可用

国际建筑工程承包合同(2021) 导语：合同就是对签订双方的一种保障，如果发生了纠纷的话，可以凭借这个合同协议书，到这个法院去起诉，或者去申请仲裁，来解决双方的纠纷，维护双方的合法权益，只要条款没违反法律意思，是双方意思自治体现就是有效的。如果需要，可以直接下载打印或用于电子存档。 发包方(以下简称甲方)：_____ 承包方(以下简称乙方)：_____ 甲方承建的_____地块±0.000 以下砼单项工程，于_____年_____月_____日，由甲方发包给乙方采用包工方式进行施工。为了明确工程内容及双方责任，本着互相协助及分工负责等原则，根据本工程的情况，特商定如下条款，共同遵守执行： 一、工程内容： 按_____地块整套施工图纸中基础分部±0.000以下施工图纸与设计变更单的所有砼工程项目。 1)工作范围包括：小面积的现浇砼构件、阳台栏板、构造柱和圈梁等各种小型构件。 2)工作内容包括：接砼管、湿润模板、补模板缝、操作面模板铺设、下料、砼面找平、振捣及清理落地砼等全部操作过程(不包括墙、柱、板接头砼凿毛和砼养护)。做到工完场清，即出料口的整理及道路的清理清扫。 二、承包造价： 按现场实际发生的砼量计算，每立方_____元(该承包单价

国际土木工程建筑承包合同(中英文对照)完整版

国际土木工程建筑承包合同(中英文对照)完整版 In the case of disputes between the two parties, the legitimate rights and interests of the partners should be protected. In the process of performing the contract, disputes should be submitted to arbitration. This paper is the main basis for restoring the cooperation scene. 【适用合作签约/约束责任/违约追究/维护权益等场景】 甲方：________________________ 乙方：________________________ 签订时间：________________________ 签订地点：________________________

国际土木工程建筑承包合同(中英文 对照)完整版 下载说明：本协议资料适合用于需解决双方争议的场景下，维护合作方各自的合法权益，并在履行合同的过程中，双方当事人一旦发生争议，将争议提交仲裁或者诉讼，本文书即成为复原合作场景的主要依据。可直接应用日常文档制作，也可以根据实际需要对其进行修改。 part工general conditions 第一章总则 definitions and interpretation 定义和释义 1．（1）in the contract，as hereinafter defined，the following words and expressions shall have the meanings hereby assigned to them，except where the context otherwise requires：

规划用语中常用英文对照 Dec2011

Contents 目录 Overall Site总场地 (场地) Global position地理位置 (全球定位) Location Plan位置图 (Regional Plan 区位图) Site photos现场照片 Vision规划远视 (规划远景) Overall master plan总体规划 Concept plan概念图 Multi-cultural area-concept plan多元文化区 - 概念图 Hot spring well-being area-concept plan温泉安康区 - 概念图 Agri-recreational area-concept plan休闲农业区 - 概念图 Outdoor sports户外运动区 Land use schedule用地指标 Land use plan用地规划图 Circulation交通流线 Infrastructure基础设施配套 (Infrastructure and Amenities 基础设施及配套设施) Infrastructure plan基础设施配套图 (Infrastructure and Amenities Plan/Diagram 基础设施及配套设施图) Ecology environment protection生态环境保护 (Ecological Environment Conservation) Planning basis规划根据 Investment returns analysis投入产出分析 (CES Cost Effectiveness Analysis) Event calendar项目览表 (Programming Diagram/Calendar) E x amp l e s案例 (Case Study/ Precedents) Detail plan大样图 Shadow studies日照分析图 (Shadow Analysis) Building height建筑高度

扬州大学建筑与土木工程

工程硕士专业学位（建筑与土木工程领域） 研究生培养方案 一、培养目标 培养建筑与土木工程领域应用型、复合型高层次的工程技术人才与管理人才，能够胜任大、中型企业建筑工程技术的研究、开发、应用及管理工作，也可以在工科教育、行政机关等企事业单位和管理部门从事相关的教学、科研和管理等工作。具体要求如下：1．坚持德、智、体全面发展的方针和“三个面向”的时代要求，热爱社会主义祖国，拥护中国共产党的领导，学习马列主义、毛泽东思想、邓小平理论和“三个代表”的重要思想，遵纪守法，具有良好的学术道德和科研作风，具有合作精神和创新精神，积极为国家的现代化建设事业服务。 2．坚持理论与实践相结合，夯实基础，强调实践，重在应用。掌握建筑与土木工程领域坚实的基础理论、宽广的专业与管理知识，掌握解决该工程领域工程问题的先进方法和技术手段。具有综合应用先进方法和技术手段解决该工程领域实际工程问题的能力；具有创新意识和从事新设计、新技术、新工艺、新材料、新产品的研制与开发能力；具有独立担负工程技术或工程管理工作的能力。 3．具备阅读本领域外文资料及初步运用外语进行交流的能力。 二、研究方向 本领域设置建筑学、建筑工程、交通土建工程、岩土工程、市政工程、工程管理等6个研究方向，详见表一。 表一：工程硕士专业学位（建筑与土木工程领域）研究方向

三、培养方式 工程硕士研究生的培养实行学校与工程单位联合培养的方式。攻读工程硕士专业学位人员采取进校不离岗、集中与分散相结合的方式进行在职学习，不脱离现职和生产实际，课程学习实行弹性学分制。 1．双导师制 工程硕士生的培养采用校内外导师联合培养的方式。校内导师由具有工程实践经验的教师担任，校外导师由学校聘任工程单位中业务水平高、责任心强的具有高级职称的工程技术人员担任。校内导师是研究生培养的第一责任人，具体负责个人培养方案的制定、课程设置、教学实践活动等工作的组织协调。校外导师协助校内导师共同负责研究生论文的选题及其相关的工程设计、技术改造、试验研究和论文撰写等环节的指导工作。导师应教书育人，关心研究生的成长，引导他们走德、智、体全面发展的道路。 2．课程学习与工程设计并重 工程硕士研究生既要深入掌握坚实的基础理论和本专业的专门知识，又要通过学位论文培养从事科学研究和胜任专门技术工作的能力。特别要加强研究生综合能力和素质的培养，包括创新能力、活动能力和适应能力的培养。研究生要尊敬师长，虚心学习，博采众长，积极进取。 3．产学研联合培养 工程硕士研究生采用在校内修读课程学分，到“产学研”研究生联合培养基地开展科学研究或工程设计研究并完成学位论文的产学研联合培养方式。充分发挥高校、科研部门和企事业单位的自身优势和特色，培养高层次应用型人才。 四、学习年限 学习年限为3年，最长不超过5年。课程学习实行学分制，按规定修满课程学分、完成所有培养环节和论文工作，并通过论文答辩，方可毕业。在校学习时间累积不少于6个月。 五、课程设置及学分分配 工程硕士研究生课程分为学位课、必修课和选修课三类，同时必须完成必修环节。本工程领域工程硕士研究生课程学习的最低学分要求为30学分，其中学位课程13学分，必修课程9学分，必修环节3学分。具体课程设置见表二。 表二：工程硕士专业学位（建筑与土木工程领域）课程设置及学分分配

对外建筑工程承包合同模板

建设工程施工合同（对外） 对外建筑工程承包合同 建筑工程承包合同是发包方（建筑单位）和承包方（施工单位、勘察设计单位）为完成某建筑工程而确立相互权利义务关系的协议。国际工程承包合同一般具有以下法律特点： １．具有国际性。要紧表现在两个方面：一是合同的当事人是属于不同国家或地区的公司、法人；二是承包人须在外国履行其全部或大部分合同义务，即合同的履行地是在承包人所属国以外的其它国家或地区，故涉及到复杂的法律适用问题。 ２．需要巨额资金，故合同标的常常专门大，交易中通常都需要各种各样的银行担保。 ３．履约期长。 ４．风险较大。为减少风险，合同中除预订有货币条款和不可抗力条款外，通常还含有价格调整条款、困难情势条款等。

对外建筑工程承包合同能够分为总承包合同、分包合同、固定总价合同和成本加酬金合同等。以下列举的是一个总承包合同： 土木工程建筑承包合同 第一章一般条款 定义和释义 １．１在本合同中，除按上下文另具意义者外，下列词语应解释如下： “业主”指第二章中所指定的雇用承包人的一方或其权利合法继承人，但不包括业主的受让人，经承包人同意者除外。 “承包人”指标书已被业主同意的某个或某些人、商行或公司，包括其他人代表，继承人和业经认可的受让人。 “工程师”指第二章中所指定的工程师，或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其它工程师。 “工程师代表”指任何常驻工程技术人员、监理工程师，或由业主或工程师随时任命的履行本合同第二条规定职责的任何工程现场监督，

其权限上工程师书面通告承包人。 “工程”包括永久性工程和临建工程。 “合同”指合同条款、技术规范、图纸、标价的建筑工程清单、单价和价格表（假如有），还可指标书、同意证书以及承包协议（如已完成）。 “合同价格”指在同意证书中确定的数额，可按本合同以下条款规定增减。 “建筑设备”指工程施工和维修中或有关施工和维修所需的全部设备或物品，不论任何性质，但不包括旨在构成或正在构成永久性工程某一部分的材料或其它物品。 “临建工程”指工程施工或维修或有关工程施工或维修所需的各种临时工程。 “永久性工程”指按合同将施工和维修的永久工程。 “技术规范”指在标书或任何标书更改中提及的规范，或由工程师随时可能增加或书面同意增加的部分。 “图纸”指技术规范中规定的图纸，经工程师书面同意对此种图纸所作的任何更改，以及可由工程师随时提供或书面认同的其他图纸。 “工地”指工程师设计的永久性或临建工程施工所需的土地及其他场地，包括地面、地下、在之上或通过部分，以及由业主所提供的用作

中英文工程合同

Contract of Construction Project 合同编号：Contract Number: 工程名称：Project Name: 发包方（甲方）： Employer (Party A): 承包方（乙方）： Contractor (Party B): 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1．工程地点：Project site: 2. 工程范围：Scope of project 3. 工程造价：人民币元整(该造价为包工包料价) Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials) 第二条施工准备Article 2, Preparation for construction 1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2．乙方：. Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. ②组织施工管理人员和材料、施工机械进场； Organize construction management staff and construction materials, construction machinery enter the Site. ③负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集处。 Be responsible for keeping public places clean during construction and packing

职称头衔中英文对照

称谓英文名称大全中英文词语对照 校长（大学）president of Beijing University 校长（中小学）principal/headmaster of Donghai Middle School 院长（大学下属）dean of the Graduate School 系主任（大学学院下属）chair/chairman of the English Department 会长/主席（学/协会）president of the Student Union, Shanghai University 厂长（企业）director of the Machine Tools Manufacturing Plant 院长（医院）director of Huandong Hospital 主任（中心）director of the Business Center 主任（行政）director of Foreign Affairs Office 行长（银行）president of the Bank for International Settlements 董事长（企业）chairman of the Board of Directors 董事长（学校）Chairmen of the Board of Trustees 首席长官的汉语称谓以“总……”表示，而表示首席长官的英语称谓语则常带有chief, general, head, managing 这类词，因此当翻译冠以“总”字的头衔时，需遵循英语头衔的表达习惯： 总书记general secretary 总工程师chief engineer 总会计师chief accountant 总建筑师chief architect 总编辑chief editor; editor-in-chief; managing editor 总出纳chief cashier; general cashier 总裁判chief referee

建筑和土木工程领域土木学科

建筑与土木工程领域（土木学科） 【430114】 一、领域简介 国务院学位委员会和国家教委于1997年联合发文设立工程硕士专业学位，同济大学为首批获得培养工程硕士专业学位教育的院校之一，从1998年9月开始招生工程硕士专业学位研究生，其中包括“建筑与土木工程”领域。本领域中的结构工程、桥梁与隧道工程、岩土工程等学科作为国家级重点学科，有着十分强实的师资和科研力量，为国民经济的建设培养了众多的应用型、复合型的人才。现有教学、科研人员近300名，其中工程院院士4名，正高级职称87名，副正高级职称100名，这些师资中有许多是成就卓著、享有国际声誉的著名专家、学者，引领着国内土木工程学科的发展。 本领域在人才培养、社会服务、科学研究、国际合作等方面取得了丰收成果。近三年招收工学博士研究生435名、工学硕士研究生1163名、工程硕士研究生584名，已与欧美、东南亚国家的许多大学和机构建立了合作关系，经常开展师生访问、学术交流、共同研究活动和项目，主办多次国际学术会议。主持完成了国家攀登B计划、国家863计划、国家自然科学基金重点项目、国家杰出青年基金项目、国家科技部、建设部、教育部、上海市科委、建委、教委等资助的大量纵向科研项目及国际合作重点项目，获得国家级、省部级科技进步奖百余项。 二、培养目标 1.工程硕士专业学位研究生是为工矿企业、工程建设单位培养应用型、复合型高层次工程技术和工程管理人才，工程硕士专业学位获得者应较好地掌握建设有中国特色社会主义理论；拥护党的基本路线和方针、政策；热爱祖国，遵纪守法；具有良好的职业道德，积极为社会主义建设服务，为本单位、本企业服务。 2. 工程硕士专业学位获得者应具有良好的工程实践素质，掌握本工程领域内坚实的基础理论和宽广的专门知识，以适应目前所承担的工作和科技发展的需要。其中数学课的要求主要是掌握解决实际问题的数学方法；外语课以提高阅读能力训练为主，要求能比较熟练地阅读本专业的外文资料；专业课可根据本工程领域的覆盖面分成若干组设置，研究生根据工矿企业、工程建设单位的需要及本人的实际情况选修课程。 3.身体健康。

建设工程施工合同(对外)实用版

YF-ED-J1637 可按资料类型定义编号 建设工程施工合同（对 外）实用版 An Agreement Between Civil Subjects To Establish, Change And Terminate Civil Legal Relations. Please Sign After Consensus, So As To Solve And Prevent Disputes And Realize Common Interests. （示范文稿） 二零XX年XX月XX日

建设工程施工合同（对外）实用 版 提示：该合同文档适合使用于民事主体之间建立、变更和终止民事法律关系的协议。请经过一致协商再签订，从而达到解决和预防纠纷实现共同利益的效果。下载后可以对文件进行定制修改，请根据实际需要调整使用。 对外建筑工程承包合同 建筑工程承包合同是发包方（建筑单位） 和承包方（施工单位、勘察设计单位）为完成 某建筑工程而确立相互权利义务关系的协议。 国际工程承包合同一般具有以下法律特点： １．具有国际性。主要表现在两个方面： 一是合同的当事人是属于不同国家或地区的公 司、法人；二是承包人须在外国履行其全部或 大部分合同义务，即合同的履行地是在承包人 所属国以外的其它国家或地区，故涉及到复杂

的法律适用问题。 ２．需要巨额资金，故合同标的常常很大，交易中通常都需要各种各样的银行担保。 ３．履约期长。 ４．风险较大。为减少风险，合同中除预订有货币条款和不可抗力条款外，通常还含有价格调整条款、艰难情势条款等。 对外建筑工程承包合同可以分为总承包合同、分包合同、固定总价合同和成本加酬金合同等。以下列举的是一个总承包合同： 土木工程建筑承包合同 第一章一般条款 定义和释义 １．１在本合同中，除按上下文另具意义者外，下列词语应解释如下：

土木工程建筑承包合同中英文对照范文

土木工程建筑承包合同中英文对照范文 PART工GENERAL CONDITIONS 第一章总则 DEFINITIONS AND INTERPRETATION 定义和释义 1．（1）In the Contract，as hereinafter defined，the following words and expressions shall have the meanings hereby assigned to them，except where the context otherwise requires： 1．1在本合同中，除按上下文另具意义者外，下列词语应解释如下： （a）'Employer' means the party named in Part II who will employ the Contractor and the legal successors in title to the Employer，but not，except with the consent of the Contractor，any assignee of the Employer． “业主”指第二章中所指定的雇用承包人的一方或其权利继承人，但不包括业主的受让人，经承包人同意者除外。 （b）“Contractor”means the person or persons，firm or company whose tender has been accepted by the Employerand includes the Contractor’s personal representatives，successors and permitted assigns． “承包人”指标书已被业主接受的某个或某些人、商行或公司，包括其个人代表，继承人和业经认可的受让人。

建筑工程内部承包合同完整版

XXX建筑工程有限公司 工程施工内部承包合同 甲方：XXX建筑工程有限公司 乙方：，身份证： 为加强建筑工程内部承包管理，确保工程质量、安全生产，明确公司与项目承包人之间责、权、利关系，甲、乙双方在协商一致、平等自愿的基础上签订以下合同条款： 一、项目概况： 1.1、工程名称及地点： 1.2、合同价款（暂定）： 1.3、合同工期： 二、承包方式 2.1、乙方承包的工程内容为甲方与（以下称发包方）签订的《合同》（以下称《施工合同》）所规定的全部内容，包括甲方所作出的投标承诺、技术要求、工程质量保修书的承诺、补充协议等与工程有关的权利、义务的全部内容，乙方自愿无条件执行并完成。 2.2、乙方以包人工、包材料、包机械、包质量、包安全、包工期、包文明施工的方式，承担全部工程施工，该工程采取由乙方自筹资金、独立核算、自负盈亏，由乙方承担因本项目承包经营和施工所发生的一切税、费、各种开支费用等，承担承包风险，并享有承包利润，该工程的所有债权、债务（包括因该工程导致甲方所受到的处罚）等均由乙方全部享有和承担。 2.3、乙方根据施工需要自行组织施工、管理人员的配备和进驻施工现场，所有施工、管理人员均由乙方进行管理，发生纠纷乙方负责处理，给甲方造成损失的，乙方负责赔偿。 2.4、乙方是本工程项目内部承包者，不得将工程转包或分包给其它单位、个人施工或经营。 2.5特别约定： 2.5.1本合同履行过程中，甲、乙双方不构成直接的工程款结算关系，如果发包方未能支付工程款，甲方不承担向乙方的付款责任，乙方亦不得以任何理由向甲方主张权利； 2.5.2如果乙方向发包方催要款项需甲方配合，甲方给予协助，所发生的费用由乙方承担。 2.5.3若发包方拖欠工程款、保证金、质保金等，乙方应在得到甲方书面授权的情况下，以甲方名义通过协商、仲裁或诉讼的方式解决，所产生的费用全部由乙方承担； 2.5.4乙方不得因发包方违约而向甲方主张权利。 2.6 管理费缴纳： 2.6.1乙方按工程决算总价款（包括附属及零星工程）的%向甲方上缴管理费（不含税，税金由甲方另行代扣代缴），凡因本工程施工而发生的应上缴的各项税、费（包括营业税、所得税等）以及所有项目人员工资全部由乙方承担，甲方不承担任何税、费等一切费用；

完整word版装修工程承包合同中英文

装修工程承包合同(中英文） Contract of Construction Project 合同编号： Contract Number: 工程名称： Project Name: 发包方（甲方）：工程设计顾问（北京）有限公司 Employer (Party A): International Consulting Engineers ( Beijing) Limited 承包方（乙方）：中寰艺高建筑装饰工程有限公司 Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1．工程地点： ,Project site: Scope of project 工程范围：．2． 3．工程造价：人民币元整 (该造价为包工包料价) 3, Project cost: PMB Yuan only (Cost of this contract is the contract price for labor and materials) 第二条施工准备 Article 2, Preparation for construction 1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2．乙方：. Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance

天大建筑与土木工程研究方向

2.11 建筑与土木工程 一、概述 建筑与土木工程是基本建设的重要工程领域，是研究和创造人类生活需求的形态环境和各类工程设施的建造与完善。作为建筑与土木工程领域，不仅涉及区域与城市规划、工业与民用建筑物的设计，而且还涉及各类工程设施与环境的勘测、设计、施工和维护。 二、培养目标 本领域的工程硕士学位获得者应掌握较为扎实和系统的建筑与土木工程领域的基本理论及其宽广的专业知识，了解相应学科的前沿发展动态，具有一定的科研能力，具有运用先进技术方法解决在相应工程领域的规划勘测、设计、施工和维护方面的问题，具有独立担负相应工程领域的技术或管理工作的能力。至少要掌握一门外语，能熟练地阅读本专业领域的外文资料，具有熟练掌握计算机的应用能力。 三、领域范围 从学科上划分，该工程领域涉及建筑学和土木工程两大学科。 主要范围：区域规划、城市规划、城市设计、建筑设计、装饰工程、结构工程、岩土工程、市政工程、桥梁与隧道工程、道路工程、防灾减灾工程及防护工程、建筑材料、水文结构工程、水利水电工程、港口海岸及近海工程、水力学及河流动力学、水文学及资源、建筑经济与管理等。 相关领域：交通与运输工程、测绘工程、水利工程、环境工程、环境科学、计算机应用技术。 四、课程设置 基础课：自然辩证法、科学社会主义理论、外语、计算机应用技术和三门因研究方向不同而设置的基础课程。对于土木工程领域，设数值分析、工程设计原理、工程测试技术等；对于建筑学领域，设现代建筑引论、现代建筑评论、现代建筑（规划）设计等。 技术基础课：对于土木工程领域，设工程弹塑性力学、高等土力学、建筑经济与管理、C＋＋与数据结构、基础工程、优化原理与方法等；对于建筑学领域，设环境心理学、现代建筑物理、绿色建筑导论、古城保护、规划理论与方法、城市社会学等。 专业课：根据联合培养单位的行业发展需求，由双方按工程、项目实际情况确定课程。 上述课程可定为学位课程和非学位课程。课程学习总学分不少于28学分。 五、学位论文 论文可以是区域规划、城市规划、村镇规划、小区规划等；可以是工业与民用建筑的建筑和结构设计，桥梁和隧道设计，地下工程设计，勘测设计，建筑、桥梁、隧道、地下及其他工程施工技术方案，施工监理，室内设计和装满设计等；也可以是设计理论、方法的研究，结构抗震、抗风、防火等理论和方法的研究，土壤力学、建筑基础加固技术的研究等。 工程设计类的学位论文主要从以下几个方面来考核： 1、解决工程实际问题，有明确的工程应用背景和应用价值； 2、对国内外文献资料的分析与综述水平；